• Michael T. Callahan on Greg Opinski Construction, Inc. v. City of Oakdale, 99 Cal. App. 4th 1107, 132 Cal. Rptr. 3d 170 (2011) (PDF)
 
 
Shop by Jurisdiction
Shop by Practice Area
Shop Products
View ALM Products

View a different catalog:
Michael T. Callahan on Greg Opinski Construction, Inc. v. City of Oakdale, 99 Cal. App. 4th 1107, 132 Cal. Rptr. 3d 170 (2011) (PDF)

Michael T. Callahan on Greg Opinski Construction, Inc. v. City of Oakdale, 99 Cal. App. 4th 1107, 132 Cal. Rptr. 3d 170 (2011) (PDF)

Discusses Greg Opinski Construction, Inc. v. City of Oakdale, in which the California Court of Appeal held that a contractor could not defend an owner's claim for liquidated damages because the contractor had not requested a time extension while the project was in progress.


Availability: In Stock
Publisher :LexisNexis Emerging Issues Analysis
Format: Electronic, 6 Pages , PDF

ISBN: 9781422429983

5/16/2012
 
$57.00
Less More




    In this article, Michael T. Callahan discusses Greg Opinski Construction, Inc. v. City of Oakdale, in which the California Court of Appeal held that a contractor could not defend an owner's claim for liquidated damages because the contractor had not requested a time extension while the project was in progress. Mr. Callahan provides valuable insight into the implications of the case for any party asserting or defending a claim for delay.

     

    Michael T. Callahan, Esq., has been involved with the construction industry for the past thirty-five years. He maintains an active consulting practice in the measurement and responsibility of delay, along with the quantification of additional performance costs and other construction and design-related matters. He earned a B.A. from the University of Kansas and both a J.D. and LL.M. from the University of Missouri-Kansas City. He is currently President of CCL Construction Consultants, Inc. and is a Contributing Author to Construction Law, a Contributing Editor of the Construction Law Digest, and the Co-Author of Discovery in Construction Litigation as well as other books for other publishers. Mr. Callahan is also a frequent arbitrator, negotiator, and mediator.

     

    Ask the LexisNexis experts - and get a complete answer based on today’s law.

     

    An authoritative analysis of important cases, codes, statutes, rulings, emerging issues or legal topics is available now - through LexisNexis Emerging Issues Analysis. The brain trust of LexisNexis authors - thousands of recognized authorities who develop the respected Matthew Bender’, Mealey’s and Martindale-Hubbell’; treatises and articles - produce this highly specific content. Each commentary covers an important case, code, statute, ruling or emerging issue such as subprime, nanotechnology, or climate change. More current and concentrated than treatises and more analytical than news, Emerging Issues Analysis bridges the information gap between the two, providing quick expert analysis of current developments in law.

     

    Emerging Issues Analysis PDFs should be purchased individually or accessed through Lexis.com if you have a subscription.

     

    (6347)

     

     

FATCA Compliance
The item you are trying to order is restricted to a quantity of 1 per order. Please complete the current order and place a new order for additional copy.
We are currently experiencing difficulties in adding this product to the cart. Please contact customer support at 1-800-543-6862 for assistance. You may continue to shop for other products in the store.